Sun Capital Energy Terms of Service

Last Updated: March 31, 2025

Welcome to Sun Capital Energy. Please read these Terms of Service (“Terms”, “Agreement”) carefully before using our website (www.suncapitalenergy.com) or engaging with our digital services, estimate requests, and communication platforms (collectively, the “Services”).

By accessing or using our Services, clicking "Submit", or opting into our communications, you agree to be bound by this Agreement and our Privacy Policy. If you do not agree to all of these terms, you must not use our Services.

1. Nature of Services & Business Disclosures

Sun Capital Energy Inc provides residential and commercial solar energy consultations, engineering designs, and professional solar installation services.

Licensing & Insurance: Sun Capital Energy Inc is a fully licensed, bonded, and insured solar contractor operating in the State of California. All structural and electrical installation operations are performed strictly in compliance with the California Contractors State License Board (CSLB) and local building codes.

Contractor License: CA License #1021860

Eligibility: You must be at least 18 years of age and the legal owner (or authorized agent of the owner) of the property for which solar services, estimates, or consultations are being requested.

2. Information Request & Free Estimations

By requesting a solar estimate, custom quote, or savings analysis through our website forms, you agree that:

All information you provide (utility bill details, energy consumption patterns, contact information, and property address) is accurate and complete.

Requesting a quote or submitting a digital form does not constitute a binding contract for a solar installation. A formal, separate written Home Improvement Contract (HIC) specifying final pricing, engineering blueprints, equipment warranties, and project milestones must be signed by both parties before any physical project installation work begins.

3. Mobile Terms of Service & SMS Disclosures (A2P 10DLC Compliance)

Sun Capital Energy Inc utilizes automated communication systems to deliver project updates, appointment reminders, and promotional messages via text (SMS). By providing your mobile number and opting into our communication channels, you agree to the following terms:

Program Description: Subscribers can expect to receive automated or manual SMS notifications regarding solar consultation scheduling, design confirmations, engineering/permit updates, project installation timelines, and occasional promotional solar offers from Sun Capital Energy Inc.

Message Frequency: Message frequency varies based on your stage in the solar installation process or your active interactions with our team.

Cost Disclosure: Message and data rates may apply for any messages sent to you from us and to us from you. Check with your wireless provider for details on your text or data plan.

Opt-Out Instructions: You can cancel the SMS service at any time. Text "STOP" to unsubscribe. Upon sending "STOP," we will send you an SMS message to confirm that you have been unsubscribed. After this, you will no longer receive SMS messages from us. To rejoin, simply sign up or request information through our website forms as you did initially.

Customer Support: For assistance with our text program, Text "HELP" for help, or email us directly at [email protected].

Carrier Liability: Mobile carriers (including but not limited to AT&T, Verizon, T-Mobile, etc.) are not liable for delayed or undelivered messages.

Privacy Link: For privacy-related inquiries, please refer to our Privacy Policy at: www.suncapitalenergy.com/privacy-policy.

4. Intellectual Property & Website Use

All content, logos, graphics, text, custom solar savings calculators, and software code displayed on this website are the intellectual property of Sun Capital Energy Inc or its licensed technology partners. You are granted a limited, non-exclusive, non-transferable license to access the site for personal, non-commercial exploration of solar services. You agree not to scrape, copy, modify, or reverse-engineer any portion of the website.

5. Disclaimer of Warranties

Our digital services, online estimate tools, and website information are provided on an "as is" and "as available" basis without warranties of any kind, either express or implied. Sun Capital Energy Inc does not guarantee that the website functions will be uninterrupted, error-free, or free of viruses. Actual solar production savings, system performance metrics, and tax incentive eligibility vary based on property orientation, roof shading tracking, utility company net-metering policy changes, and individual financial profiles.

6. Limitation of Liability

To the maximum extent permitted by law, Sun Capital Energy Inc, its directors, employees, or subcontractors shall not be liable for any indirect, incidental, special, consequential, or punitive damages arising out of your access to, or inability to access, this website. In no event shall our total liability for web-based interactions exceed $100 USD. Final liabilities regarding physical solar installation workmanship and structural warranties are exclusively governed by your signed Home Improvement Contract, not this digital document.

7. Dispute Resolution & Governing Law

This Agreement and any dispute arising from your digital use of this website shall be governed by and construed in accordance with the laws of the State of California, without regard to conflict of law principles.

Any legal claim or controversy arising out of or relating to these digital terms shall be settled by binding arbitration in Los Angeles, California. You explicitly waive your right to a trial by jury and agree not to participate as a plaintiff or class member in any class-action lawsuit against Sun Capital Energy Inc.

8. Changes to These Terms

We reserve the right to modify these Terms of Service at any time. Revisions will become effective immediately upon posting to this URL page. Your continued use of our platform or communication services following updates constitutes your binding acceptance of the revised terms.

9. Contact Us

If you have questions, comments, or regulatory inquiries regarding these Terms, please contact us at:

Company Name: Sun Capital Energy Inc

Email: [email protected]

Website: www.suncapitalenergy.com